Shopping Mall Public Liability Insurance Renovation Public Liability Insurance Event Public Liability Insurance

web1280Vid1-shoppingmallrenovationinsurance

Shopping Mall Public Liability Insurance
Renovation Public Liability Insurance
Event Public Liability Insurance
By ACPG
+6011-12239838. +603-92863323
 
Public Liability Insurance
Arranged By
ACPG Management Sdn Bhd
Head Office
158-3-7, Blok 158, Kompleks Maluri,
Jalan Jejaka, Taman Maluri, Cheras,
55100 Kuala Lumpur, Malaysia.
+603-92863323
 
Public Liability insurance is considered essential in businesses which involve regular interactions between the members of the public and the company such as retail businesses, restaurants, clinics, contractors, renovators, installers and many more.
 
The Public Liability insurance covers your legal liability to a third (3rd) party as a result of an accident happening in connection with your business operations.
 
The insurance indemnifies you against all sums which you become legally liable for damages and claimant’s costs and expenses in respect of:
Bodily injuries including illnesses to any person.
Losses or damages to property.
 
Legal expenses incurred in your legal proceeding defence.
Public Liability insurance protects our policyholders against legal liabilities arising in connection with their business operations.
 
Coverage may include products, completed operations, premises and operations, personal injury and contractual liability.
 
These are some of the types of coverage requested:
Premises and operations coverage for bodily injury or property damage incurred on their premises and/or as a result of their business operations
 
Product liability coverage for bodily injury or property damage incurred through the use of the product manufactured, distributed or sold
 
Completed operations coverage for bodily injury or property damage incurred because of a defect in a completed project.
Public Liability Insurance for
 
Construction Contractors and Sub Contractors.
Renovation Contractors and Sub Contractors.
Installation Contractors and Sub Contractors.
Signboard Owner, Contractors and Sub Contractors.
Manufacturing and Factory Owners
Office Owners and Tenants
Shop, Retail Outlets Owners and Tenants.
Shopping Mall Owners, Tenants and JMB, MC, PMC, property management company and management office.
 
Public Liability Insurance for Malaysia Kuala Lumpur Shopping Mall Listing
AEON Mahkota Cheras Shopping Mall Public Liability Insurance
AEON Alpha Angle Shopping Mall Public Liability Insurance
AEON Maluri Shopping Mall Public Liability Insurance
Alamanda Putrajaya Shopping Mall Public Liability Insurance
Amcorp Mall Shopping Mall Public Liability Insurance
Ampang Park Shopping Mall Public Liability Insurance
Ampang Plaza Shopping Mall Public Liability Insurance
Ampang Point Shopping Mall Public Liability Insurance
Atria Shopping Mall Public Liability Insurance
Avenue-K Shopping Mall Public Liability Insurance
Bangsar Village Shopping Mall Public Liability Insurance
Bangsar Shopping Mall Public Liability Insurance
Bangsar South Shopping Mall Public Liability Insurance
Bangsar Trade Centre Shopping Mall Public Liability Insurance
Berjaya Times Square Shopping Mall Public Liability Insurance
Bukit Raja Shopping Mall Public Liability Insurance
Brem Mall Shopping Mall Public Liability Insurance
Campbell Complex Shopping Mall Public Liability Insurance
Capsquare Shopping Mall Public Liability Insurance
Carrefour Kepong Shopping Mall Public Liability Insurance
Carrefour Jalan Peel Shopping Mall Public Liability Insurance
Carrefour Wangsa Maju Shopping Mall Public Liability Insurance
Cheras Leisure Mall Shopping Mall Public Liability Insurance
Da Men USJ Shopping Mall Public Liability Insurance
Digital Mall Shopping Mall Public Liability Insurance
Empire City Shopping Mall Public Liability Insurance
Endah Parade Shopping Mall Public Liability Insurance
Equine park Shopping Mall Public Liability Insurance
EVOLVE Concept Mall Shopping Mall Public Liability Insurance
Fahrenheitt 88 Shopping Mall Public Liability Insurance
Four Seasons Place Kuala Lumpur Shopping Mall Public Liability Insurance
Goldcourse Shopping Mall Public Liability Insurance
Great Eastern Mall Shopping Mall Public Liability Insurance
Hartamas Shopping Mall Public Liability Insurance
Idaman Plaza Shopping Mall Public Liability Insurance
Ikano Power Centre (IPC) Shopping Mall Public Liability Insurance
IKEA Shopping Mall Public Liability Insurance
INTERMARK Retail Podium Shopping Mall Public Liability Insurance
IOI City Mall Putrajaya Shopping Mall Public Liability Insurance
IOI Mall Shopping Mall Public Liability Insurance
Jaya One Shopping Mall Public Liability Insurance
Jaya 33 Shopping Mall Public Liability Insurance
Klang City Square Shopping Mall Public Liability Insurance
Klang Parade Shopping Mall Public Liability Insurance
Klang Utama Shopping Mall Public Liability Insurance
Komplek Muhibah Seksyen 24 Shopping Mall Public Liability Insurance
Kompleks Elektronik ACE Shopping Mall Public Liability Insurance
Kompleks Galaxy Ampang Shopping Mall Public Liability Insurance
Kompleks Kota Kajang Shopping Mall Public Liability Insurance
Kompleks Mutiara Shopping Mall Public Liability Insurance
Kompleks Centre Point Shopping Mall Public Liability Insurance
Kompleks Showplex Mont Kiara Shopping Mall Public Liability Insurance
Kompleks Sungai Buloh Shopping Mall Public Liability Insurance
Kota Raya Shopping Mall Public Liability Insurance
Low Yat Plaza Shopping Mall Public Liability Insurance
Lot 10 Shopping Mall Public Liability Insurance
Maju Junction Shopping Mall Public Liability Insurance
Metro Prima Shopping Mall Public Liability Insurance
Metro Point Kajang Shopping Mall Public Liability Insurance
Midvalley Mega Mall Shopping Mall Public Liability Insurance
One Utama Shopping Mall Public Liability Insurance
Pavillion Kuala Lumpur Shopping Mall Public Liability Insurance
Pear Point Shopping Mall Public Liability Insurance
Pertama Complex Shopping Mall Public Liability Insurance
Pingat Bazaar Shopping Mall Public Liability Insurance
Plaza City One Shopping Mall Public Liability Insurance
Plaza Metro Kajang Shopping Mall Public Liability Insurance
Plaza Shah Alam Shopping Mall Public Liability Insurance
Publika Shopping Mall Public Liability Insurance
Puchong Tesco Shopping Mall Public Liability Insurance
Pudu Plaza Shopping Mall Public Liability Insurance
Roppongi Cyberjaya Shopping Mall Public Liability Insurance
SACC Mall Shopping Mall Public Liability Insurance
Selayang Star City Shopping Mall Public Liability Insurance
Setia City Mall Shopping Mall Public Liability Insurance
Shaw Parade Shopping Mall Public Liability Insurance
SOGO Shopping Mall Public Liability Insurance
South City Plaza Shopping Mall Public Liability Insurance
Star Avenue Lifestyle Mall Shopping Mall Public Liability Insurance
Star Hill Gallery Shopping Mall Public Liability Insurance
Subang Parade Shopping Mall Public Liability Insurance
Summit USJ Shopping Mall Public Liability Insurance
Sungei Wang Plaza Shopping Mall Public Liability Insurance
Sunway Giza Shopping Mall Public Liability Insurance
Sunway Nexis Shopping Mall Public Liability Insurance
Sunway Putra Mall Shopping Mall Public Liability Insurance
Sunway Pyramid Shopping Mall Public Liability Insurance
Sunway Velocity Shopping Mall Public Liability Insurance
Suria KLCC Shopping Mall Public Liability Insurance
Tropicana City Mall Shopping Mall Public Liability Insurance
The Curve Shopping Mall Public Liability Insurance
The Gardens Mall Shopping Mall Public Liability Insurance
The Mall Shopping Mall Public Liability Insurance
The Mines Shopping Mall Public Liability Insurance
The Weld Shopping Mall Public Liability Insurance
THE 19 USJ City Mall Shopping Mall Public Liability Insurance
Vivahome Shopping Mall Public Liability Insurance
Wangsa Walk Mall Shopping Mall Public Liability Insurance
 
ACPG celebrations 30 years Anniversary in year 2019.
 
We ACPG Management Team and Staffs sincere thanks for your loyalty support and wish your continue trust and support ACPG to achieve 30 years Great Success in Malaysia insurance industry.
 
ACPG will continue commit to arrange more comprehensive insurance products and services to achieve next higher level achievement.
 
Buy Online Motor Insurance Policy at http://www.insuranceonlinepurchase.com
Buy Online Motorcycle Insurance Policy at http://www.insuranceonlinepurchase.com
Buy Online Travel Insurance Policy at http://www.insuranceonlinepurchase.com
Buy Online Pet Insurance Policy at http://www.insuranceonlinepurchase.com
Buy Online Home Insurance Policy at http://www.insuranceonlinepurchase.com
Buy Online Personal Accident Policy Insurance at http://www.insuranceonlinepurchase.com
 
Malaysia Insurance Services, Malaysia Medical Insurance, Malaysia JMB Insurance, Malaysia Motor Insurance
 
Malaysia Insurance Corporate Agency
ACPG Management Sdn Bhd (Insurance Biz since Year 1989)
Head Office
158-3-7, Blok 158, Kompleks Maluri,
Jalan Jejaka, Taman Maluri, Cheras,
55100 Kuala Lumpur, Malaysia.
+603-92863323, +6011-12239838, +6012-6489838
 
For more information or quotation enquiry, please contact our ACPG Whatsapp Team
 
#MalaysiaPublicLiabilityinsurance
#MalaysiaShappingMallPublicLiabilityinsurance
#PublicLiabilityinsurance
#RenovationPublicLiabilityinsurance
#ContractorAllRiskinsurance
#ErectionAllRiskinsurance
#Foreignworkerinsurance
#ForeignWorkersHospitalizationandSurgicalinsurance
#ForeignWorkersinsuranceGuarantee
#FWIG
#FWHS
#SKHPPA
#ACPGManagementSdnBhd
#ACPG
Contractor Liability Insurance FB A4

Public Liability Insurance Arranged by ACPG Management Sdn Bhd

acpg100Fb_m-public-liabilityLegal Liability Insurance Malaysia (Hotline +603-92863323)

Public Liability Insurance, Personal Liability Insurance,

Business Liability Insurance, Third Party Liability Insurance,

Product Liability Insurance, Professional Indemnity Insurance,

Building Management Liability Insurance, Liability Insurance,

Employer’s Liability Insurance, Errors & Omission Insurance,

Renovation Liability Insurance, Contractor Liability Insurance, Installation Liability Insurance, Signboard Liability Insurance, Roadside Banner Liability Insurance, Event Liability Insurance, Exhibition Liability Insurance, Concert Liability Insurance, Retail Premises Liability Insurance, Restaurant Premises Liability Insurance, Food Poisoning Liability Insurance

Arranged By

ACPG Management Sdn Bhd

www.acpgconsultant.com

+603-92863323, +6011-12239838

LIABILITY COVERAGE

Liability insurance coverage protects you, your business and your employees from claims involving bodily injury or property damage, up to the limits of your policy. This policy also indemnifies you against the expense of out-of-court settlements, litigation and judgments awarded by courts.

 

ACPG BZP28

PUBLIC LIABILITY INSURANCE POLICY

This policy indemnifies you against your legal liability to third parties in connection with your business, such as bodily injury and property damage to third parties property.

Public Liability Insurance Introduction

This insurance covers the legal liability of the Insured against bodily injury to third parties and loss of or damage to third parties property caused by the Insured’s negligence in connection with the business specified in the policy.

The coverage includes expenses of litigation recoverable by claimant against the Insured or incurred with the consent of the Company.

What are the Public Liability Insurance Policy covers/benefits provided?

This policy covers your legal liability to pay compensation in respect of:-

a) bodily injury to third parties

b) damage to property not belonging to or in the custody of the Insured

as a result of accident and happening in connection with your business.

In addition, this policy also cover litigation costs and expenses incurred with the written consent of the

Company.

 

ACPG BZP25

EMPLOYER’S LIABILITY INSURANCE POLICY

This insurance indemnifies you against legal liability at law to pay compensation and claimant’s costs and expenses in respect of harm sustained by your employees in the course of employment.

Employer’s Liability Insurance Introduction

Employers may purchase this insurance which indemnifies them against their legal liability at law to pay compensation and claimant’s costs and expenses in respect of bodily injury by accident or disease sustained by the insured employees in the course of employment with them.

The coverage also includes all costs and expenses incurred with the consent of the Company.

Employees to be covered include local employees who are not eligible for contribution to the SOCSO scheme.

1. What is Employer’s Liability Insurance Policy about?

This policy covers your legal liabilities to compensate your employees for injuries by accident or disease arising out of and in the course of employment.

2. What are the Employer’s Liability Insurance Policy covers/benefits provided?

a) This policy covers your liabilities under common law for injuries to your workmen by accident or disease arising out of and in the course of employment.

b) Claimant’s costs and expenses.

 

ACPG BZP30

PRODUCT LIABILITY INSURANCE POLICY

The policy indemnifies you against all sums which you are legally liable to pay as damages or compensation in respect of bodily injury and property damage arising out of claims made against you during the period of insurance as a result of an accident caused by anything harmful or defective in your product sold or supplied by you during the period of insurance.

Product Liability Insurance Introduction

This insurance is designed to cover the legal liability of the Insured against bodily injury and property damage to users of the insured products arising out of anything harmful or defective in the insured products (or the container thereof) which are sold or supplied by the Insured.

The coverage includes expenses of litigation recoverable by claimant against the Insured or incurred with the consent of the Company.

1. What is Product Liability Insurance Policy about?

The policy indemnifies you against all sums which you are legally liable to pay as damages or compensation in respect of bodily injury and property damage arising out of claims first made in writing against you during the period of insurance as a result of an accident caused by anything harmful or defective in your product sold or supplied by you during the period of insurance.

2. What are the Product Liability Insurance Policy covers/benefits provided?

We will pay all sums which you become legally liable to pay as damages or compensation in respect of:

(a) bodily injury;

(b) property damage

as a result of a claim first made in writing against you during the period of insurance within the Territorial Limits as a result of an occurrence in connection with your products specified in the policy schedule and we will pay all costs and expenses of litigation recovered by any claimant against you and/or incurred

with the written consent of the Insurer, subject to the Limit of Indemnity as specified in the policy schedule.

 

ACPG BZP31

PROFESSIONAL INDEMNITY INSURANCE POLICY

This insurance provides indemnity to professionals (e.g. engineers, lawyers, surveyors, etc.) for any claim made against them for breach of professional duty.

Professional Indemnity Insurance Introduction

This insurance provides indemnity to professionals (e.g. engineers, lawyers, surveyors, etc.) for any claim made against them for breach of professional duty arising from any act, error or omission committed in their conduct of their professional services.

1. What is Professional Indemnity Insurance policy about?

Professionals who provide professional services owe a duty of care to their clients / third parties and

must exercise due care and skill. If their clients suffer financial losses after relying on their professional

advice, clients have the right to sue for the loss.

This policy indemnifies you against the breach of professional duty, by reason of any negligent act, error

or omission performed by you in the conduct of your profession.

2. What are the Professional Indemnity Insurance policy covers/benefits provided?

This policy covers:-

a) Compensation / claims made against you

b) Costs and expenses incurred

up to the Limit of Indemnity specified in the policy schedule.

 

ACPG Management Sdn Bhd

Head Office

158-3-7, Blok 158, Kompleks Maluri,

Jalan Jejaka, Taman Maluri, Cheras,

55100 Kuala Lumpur, Malaysia.

http://www.acpgconsultant.com

enquiry@acpgconsultant.com

+603-92863323, +6011-12239838

 

ACPG BZP28A

ACPG BZP29.jpg

ACPG BZP27.jpg

ACPG BZP24

ACPG BZP23.jpg

ACPG BZP26

Event Public Liability Insurance Malaysia

acpg100fb_exhibition-liability

Event Public Liability insurance Malaysia

Arranged By

ACPG Management Sdn Bhd

www.acpgconsultant.com

+603-92863323

Event liability insurance

For special events, you can’t plan for everything.

Markel’s event liability insurance provides coverage for damages for which you are responsible if there is an accident at your event that causes injury or property damage.

Event liability insurance provides the following primary coverage:

Bodily injury and property damage liability.

Additional insured? Never an additional charge. Many venues now require event liability insurance. Generally, the venue will be named as “additional insured” on the certificate of insurance.

Business and corporate event insurance

ACPG insurers also offers liability coverage for your business and corporate events*. Examples of some of the business events we cover include:

Business dinner

Business meeting

Corporate private party

Fundraiser dinner

Non-profit function

exhibition-liability-insurance-fb-wall-post

What is Public Liability insurance?

Covers your legal liability to third party as a result of an accident happening during the period of cover in connection with your business operations and occurring within the territorial scope.

Key coverage

Here is an overview of your coverage

Public Liability Insurance

Public Liability Insurance

You are covered for

All sums which you shall become legally liable to pay compensation in respect of

Bodily injury (including illness) to any person(s)

Loss of or damage to property

All cost and expenses of legal action

Recovered by any claimant against you

Incurred with our written consent

How much is my premium?

Your premium may vary, depending on

Indemnity limit

Any extensions to the basic cover

Our insurers underwriting requirements

Public Liability insurance is considered essential in businesses which involve regular interactions between the members of the public and the company such as retail businesses, restaurants, clinics and many more.

The Public Liability insurance covers your legal liability to a third (3rd) party as a result of an accident happening in connection with your business operations. The insurance indemnifies you against all sums which you become legally liable for damages and claimant’s costs and expenses in respect of:

Bodily injuries including illnesses to any person

Losses or damages to property

Legal expenses incurred in your legal proceeding defence

Special Events Insurance.

Multimedia Risk provides cost effective insurance solutions for your Special Event in Malaysia.

Contact us early in the event organizing stage for your event. We will then work with you and advise you on insurance arrangements and also make suggestions regarding certain considerations that could reduce risk therefore lower your premium.

As event organizers, there are numerous things that could compromise or even cause the cancellation of the project you have injected so much time and energy into. These ‘occurrences’ could be anything from the venue you had booked being shut down to your key speaker being stuck at an airport in another city.

Special Event Insurance provides short-term liability coverage for organizations or individuals hosting events such as:

Art Exhibits

Bazaars

Carnivals

Concerts

Country Events

Cultural Events

Fairs

Festivals

Fireworks Display

Parades

Street Fairs

Trade Shows/Conferences

Legal Liability Exposures for Special Events

As an occupier of premises, you and your organization are responsible for the safety of those attending the event. Occupiers must protect patrons from all foreseeable harm.

Some instances where extra precautions should be considered:

Alcohol is served.

Children/minors are in attendance.

Dangerous/hazardous activities are undertaken such as fireworks, boating, and some sports.

Gambling is involved.

Large crowds are in attendance.

Applicable permits should always be obtained from your municipal/provincial government to reduce liability relating to violations involving permits. Health requirements should also be followed.

Contact your principal, building management or related state government department for more information regarding your responsibilities regarding special events.

The types of liability often covered for Special Events include:

General Liability

Automobile Liability and Physical Damage

Third Party Property Damage

Rented Equipment, Props, Sets and Wardrobe

Participants & Spectators Medical

Malaysia Liability Insurance

Liability insurance also known as Commercial insurance protects you in the event you are sued for claims that come within the coverage of your liability insurance policy.

Types of Liability Insurance:

PUBLIC LIABILITY INSURANCE

This type of insurance would cover a business if a customer or member of the public was to suffer a loss or injury as a result of its business activities, and if that person made a claim for compensation. The insurance would cover the compensation payment plus any legal expenses.

PRODUCT LIABILITY INSURANCE

Product liability insurance covers the cost of compensating anyone who is injured by a faulty product that your business designs, manufactures or supplies.

PROFESSIONAL INDEMNITY INSURANCE

This policy is a form of liability insurance that helps protect professional advice and service-providing individuals and companies from bearing the full cost of defending against a negligence claim made by a client, and damages awarded in such a civil lawsuit.

DIRECTORS AND OFFICERS LIABILITY INSURANCE

This policy is a liability insurance payable to the directors and officers of a company, or to the organization(s) itself, as indemnification (reimbursement) for losses or advancement of defense costs in the event an insured suffers such a loss as a result of a legal action brought for alleged wrongful acts in their capacity as directors and officers. Such coverage can extend to defense costs arising out of criminal and regulatory investigations/trials as well; in fact, often civil and criminal actions are brought against directors/officers simultaneously.

WORKMEN’S COMPENSATION INSURANCE

This policy cover the employer in respect of the statutory liability under the Workmen’s Compensation Law(s) as well as at Common Law to the employees who are generally not covered under SOCSO.

This policy indemnifies the employer against all sums for which the employer shall be liable to pay compensation to any employee for personal injury sustained by accidents or occupational diseases arising out of and in the course of this employment under the Acts.

FOREIGN WORKERS’ COMPENSATION SCHEME

Employers who are employing foreign workers must comply with the statutory requirement under Section 26(2) of the Amended Act 1996 of Workmen’s Compensation Act 1952 to purchase this insurance to protect their foreign workers

This policy indemnifies the employer under the Act in respect of compensation for employment injury as well as non-employment injury sustained by your foreign workers.

FOREIGN WORKERS HOSPITALIZATION AND SURGICAL INSURANCE SCHEME

The Foreign Workers Hospitalization and Surgical Insurance Scheme (FWHS) or better known as SKHPPA is specially designed in view of increasing Hospital and Surgical charges and to reduce financial burden of the Employers of foreign workers in the event of hospital admission of their foreign workers due to accident or illness. Coverage is required before work permit is issued by Immigration Department for both new and renewal applications.

EMPLOYERS’ LIABILITY INSURANCE

This policy covers the employer because the employer may be at risk of being sued by those employees who are not protected by Workmen’s Compensation Acts or SOCSO.

This policy indemnifies the employer against liability at law to pay compensation and cost and expenses to your employees in respect of accidental bodily injury or disease arising out of or in the course of employment. The standard Common Law limit is RM1,000,000 any one accident and in the aggregate.

ACPG Management Sdn Bhd

Head Office

158-3-7, Blok 158, Kompleks Maluri,

Jalan Jejaka, Taman Maluri, Cheras,

55100 Kuala Lumpur, Malaysia.

http://www.acpgconsultant.com

enquiry@acpgconsultant.com

+603-92863323, +6011-12239838

event-liability-insurance-fb-a4

驾车人士必备的紧急通讯录! 马来西亚保险公司 + 高速公路的联系号码!

11138523_897510296979548_1132563850030421061_n

驾车人士必备的紧急通讯录!
马来西亚保险公司 + 高速公路的联系号码!
Malaysia Highway Information Listing and Malaysia Motor Insurance Emergency Assistance Contact Information.

“无论你是否有驾车,请把这篇文章分享出去。

让更多的人都知道雪隆一代的大道联系号码。

是否曾经想过,如果在回乡的路上或上班的时候,我的车子在路中央停着不会动了,而有没有熟悉的车厂可以联系,是否应该联系我们的大道公司呢?对了,就是这样,我们应该联系他们….

如您在这些大道上发生任何的事情,可第一时间联系他们。赶快查看和分享吧!

且慢!你有他们的联络号码吗?根据马来西亚的调查,高达85%的大道使用者都不知道每一条大道的联系电话号码。

为了自己以后的方便,今天是不是应该来阅读或者记下你们常用的大道联系号码呢?
(SHARE在自己的FACEBOOK Profile,如有需要就可以立刻看到咯)

Malaysia Highway Information Listing
马来西亚高速公路的联系号码

Ampang Kuala Lumpur Elevated Highway (Prolitas AKLEH)
Tel: 03-4252 3122 (Hotline)

Besraya – Operator of Besraya Highway from Istana Interchange to UPM Interchange
Tel: 03-8941 8288, 1-800-88-0999 (Besline)

Damansara- Shah Alam Elevated Expressway (DASH)
Tel: 03-7847 6264
Highway Tel: 03-4032 1233

East Coast Expressway ECE, Kuala Lumpur – Karak Highway, Kuantan, Pahang
Tel: 03 6120 3322, Fax: 03-6120 3222

East Klang Valley Expressway (EKVE)
Tel: 1300-88-3563

Gerbang Perdana
Tel: 03-7957 8322, Fax: 03-7957 9855

Grand Saga – Concession Company for Cheras-Kajang Highway
Tel: 03-9080 4988, 03-9075 0505 (Saga Ronda)

Guthrie Corridor Expressway – GCE
Tel: 1300-88-0035 (Hotline)

KESAS – Konsortium Expressway Shah Alam Selangor – Lebuhraya Shah Alam LSA
Tel: 03 5633 7188 (Hotline)

KL-Putrajaya Highway – Maju Expressway MEX

Tel: 03-8315 9111 (Highway Emergency)

Kinrara-Damansara Expressway (Kidex Skyway)
Tel: 03-6257 0812

LATAR – KL-Kuala Selangor Expressway
Tel: 03-6145 1515

LEKAS – Lebuhraya Kajang Seremban
Tel: 1800-88-8021 (Infoline), 03-8723 8021

LITRAK – Lingkaran Trans Kota Sdn.Bhd – Operator of Lebuhraya Damansara Puchong LDP
Tel: 03-7494 7333. (Helpline)

Metramac – (Ex-)Operator of Jalan Pahang, Jalan Cheras toll roads. Cheras East-West Link
Tel: 03-4256 3800

NKVE – New Klang Valley Expressway
Tel: 1800-880-000 (Plusline)

NPE – New Pantai Highway
Tel: 1300-88-1010 (NPE Infoline)

Penang Bridge Sdn Bhd PBSB
Tel: 04-398 7419

North South Highway Project -NKVE
Tel: 03-7801 6666, Fax: 03-7801 6600,1800-88-000 (PlusLine)
Tel: 07-278 2000, 07-278 8000 (Hotline)

SILK – Sistem Lingkaran-Lebuhraya Kajang Sdn Bhd
Tel: 1800-88-1997, 03-8921 0000

SKVE – South Klang Valley Expressway</strong>
Tel: 1300-88-0026 (Careline), 03-7960 7010

Stormwater Management Road Tunnel – SMART
Tel: 1300-88-7188 (Hotline), 03-9284 6924

SPRINT Lebuhraya – Sistem Penyuraian Trafik KL Barat Sdn Bhd
Tel: 03-7960 1050, 1800-6868 (Hotline)

Senai Desaru Expressway (SDE)
Tel: 07-8612 2222

Seremban-Port Dickson Highway (SPDH)
Tel: 03-7801 6666, 03-7666 4666

SUKE (Sungai Besi-Ulu Kelang Elevated Expressway)
Tel:03-4270 1540

West Coast Expressway (WCE)
Tel: 03 5131 6993

 

Car Insurance FB Wall Post

Malaysia Motor Insurance Company Emergency Assistance Contact Information
马来西亚汽车保险公司的联系号码

ACE Jerneh Motor Insurance
Emergency Hotline: 1300-88-0128

AIA Private Car Insurance
Emergency Hotline: 1300-22-1188

AIG Comprehensive Motor Insurance
Emergency Hotline: 1800-88-1033

AXA Affin Comprehensive Motor Insurance / SmartDrive
Emergency Hotline: 03-2170-8282

Allianz Comprehensive Motor Insurance
Emergency Hotline: 1800-88-6278

AmGeneral Private Motor Insurance
Emergency Hotline: 1300-88-2647

Berjaya Sompo Private Motor Insurance
Emergency Hotline: 1300-22-1188

CIMB Motor Insurance
Emergency Hotline: 1300-88-0900

Easy by RHB Easy-Insurans Kasih Motor
Emergency Hotline: 1300-22-0007

Etiqa Comprehensive Private Car Takaful Insurance
Emergency Hotline: 1800-88-6491

HSBC Comprehensive Car Insurance
Emergency Hotline: 1300-88-0980

Kurnia Comprehensive Motor Insurance
Emergency Hotline: 1800-88-3833

Liberty Comprehensive Auto Star
Emergency Hotline: 1800-88-5005

Lonpac Comprehensive Private Vehicle Insurance
Emergency Hotline: 03-7628-3833

MAA Takaful Comprehensive Motor Insurance Coverage
Emergency Hotline: 1300-22-1188 / 03-7628-3773

Maybank Comprehensive Motor Takaful Insurance
Emergency Hotline: 1800-80-6491

Pacific Insurance
Emergency Hotline: 1800-88-1629 / 03-2176-1188

P&O Motor Insurance
Emergency Hotline: 1800-88-2121

Tokio Marine Comprehensive Motor Insurance
Emergency Hotline: 1800-88-1301

Zurich Motor Insurance
Emergency Hotline: 1300-88-6222

Malaysia Insurance Directory

Public Liability Insurance
Third Party Liability Insurance
Billboard Public Liability Insurance
Banting Public Liability Insurance
Signboard Public Liabiity Insurance
Highway Billboard Public Liability Insurance
Installation Work Public Liability Insurance
Contractor Work Public Liability Insurance
Contractor All Risk Insurance

Arranged by
ACPG Manaagement Sdn Bhd
Malaysia General Insurance Risk Management Solution Provider since year 1989.
ACPG Careline +603-92863323, +6011-12239838
enquiry@acpgconsultant.com
http://www.acpgconsultant.com
http://www.facebook.com/acpg.management

ACPG Manaagement Sdn Bhd
Head Office Located
158-3-7, Kompleks Maluri,
Jalan Jejaka, Taman Maluri,
55100 Kuala Lumpur, Malaysia.
+603-92863323, +6011-12239838.

Malaysia Motor Insurance Directory

Private Use Motor Insurance Malaysia
Private Use Car Insurance Malaysia

Commercial Motor Insurance Kuala Lumpur Malaysia.
A Permit Commercial Van Motor Insurance
C Permit Commercial Van Motor Insurance
A Permit Commercial Lorry Motor Insurance
C Permit Commercial Lorry Motor Insurance

Commercial Car Insurance Kuala Lumpur Malaysia.
A Permit Commercial Van Car Insurance
C Permit Commercial Van Car Insurance
A Permit Commercial Lorry Car Insurance
C Permit Commercial Lorry Car Insurance

Malaysia Motor Insurance Kuala Lumpur
Services Provided By
ACPG Management Sd Bhd
+603-92863323, +6011-12239838.
enquiry@acpgconsultant.com
http://www.acpgconsultant.com
https://www.facebook.com/acpg.management/

ACPG Manaagement Sdn Bhd
Head Office Located
158-3-7, Kompleks Maluri,
Jalan Jejaka, Taman Maluri,
55100 Kuala Lumpur, Malaysia.
+603-92863323, +6011-12239838.

ACPG Motor Insurance Claim 01

Construction Insurance Malaysia

Contractor All Risk Insurance FB Wall Post

Construction Insurance Arranged By ACPG Management Sdn Bhd (ACPG)

A proven leader in the construction industry, ACPG Principal Insurer delivers integrated property & casualty and specialized insurance solutions which are tailored to construction risks from:

  • Residential and Commercial Projects
  • Civil Engineering Projects such as pipelines, dams, roads and rail
  • Power and Energy Projects of all sizes
  • Petrochemical and Industrial plants

Our unique industry practice group provides clients with a comprehensive spectrum of products including Project Cargo, Casualty, Surety, Environmental and Project Professional Indemnity.

Whether you’re a Principal, Property Developer, Main Contractor, we will work collaboratively with you and your broker to help develop seamless and effective risk management solutions.

OUR STRENGTHS

By working with ACPG Principal Insurer Construction Industry Practice, you will benefit from our strengths which encompass:

  • Local knowledge backed by global capability
  • Comprehensive suite of services
  • Experienced underwriting team
  • Dedicated Construction Risk Engineers
  • Superior Claims Handling and Administration
  • Consultative approach to loss prevention and mitigation
  • Tailor-made programs backed by client-centric service
  • Broad coverage
  • Long-term focus on client relationships

PRODUCT RANGE

ACPG Principal Insurer Construction Industry Practice offers a range of products and services including:

  • Contract Works
  • Delay in Start Up
  • General Liability
  • Umbrella/Excess Casualty Covers
  • Project Professional Liability
  • Environmental Pollution Liability
  • Contract Surety
  • Construction Risk Management Services
  • Marine Cargo including DSU
  • Directors & Officers Liability
  • Terrorism

CONSTRUCTION INSURANCE PRODUCTS

Construction All Risks – Civil Engineering

This insurance provides contractors involved in hydro projects, motorways, railways and pipelines with annual cover or single risk project cover.

PRODUCT HIGHLIGHTS

  • We have a strong track record of leading the insurance of large and complicated project contracts
  • We are recognised technical expertise in the sector
  • We seek to develop long-term relationships with clients

COVER

Our standard cover includes:

  • Consequences of design
  • Extended maintenance
  • Natural catastrophes
  • Property damage only
  • Primary third party liability

Cover can be extended to include:

  • Delay in start up
  • Full design

Erection all Risks

ACPG Principal Insurer Erection All Risks (EAR) insurance includes the erection and installation of electrical or mechanical plant and machinery. It’s ideal for mechanical and electrical contractors looking for annual contract cover or developers, manufacturers, power and energy companies involved in large and complex installations.

Our target areas include construction of power plants, oil and gas facilities and other heavy industries such as steel, aluminium and cement, as well as traditional light engineering projects such as bottling plants and pharmaceuticals.

PRODUCT HIGHLIGHTS

  • Experience in writing many types of risks from standard installation contracts to large scale power and energy plants
  • A strong track record of leading the insurance of large and complex project contracts
  • The capacity to cover contracts in many overseas territories
  • Highly experienced risk engineers who can assist in risk management and risk reduction, as well as ensure that standards are maintained during the erection and installation works to help reduce losses

COVER

  • Our standard EAR cover is for the erection and / or installation of electrical or mechanical plant and machinery globally.
  • It can also cover losses during the testing and commissioning prior to hand-over and damage during the contractual maintenance period.
  • Cover can be provided for movement and re-erection of machinery along with testing, commissioning and maintenance of installed machinery.
  • An ‘all-risks’ cover that includes breakdown and explosion during testing and commissioning.
  • Available on contracts overseas subject to some territorial and environmental peril limitations.
  • The standard insurance offers cover for defective design under the LEG 2/96 wording and damage to installed equipment during maintenance visits. This can be extended to give wider defective design cover and either extended or ‘full’ or guarantee maintenance.

Foreign Workers Insurance

Employees are a company’s greatest asset therefore it is essential for an employer to get their employees protected.

Being one of the approved panel insurance companies to provide foreign workers insurance, ACE Jerneh has three products designed to provide financial relief for the employer in the event of death, hospitalization or repatriation of their foreign workers.

Foreign Workers Compensation Scheme (FWCS)

As provided under Section 26(2) of the Workmen’s Compensation Act 1952, it is mandatory for every employer to insure all their foreign workers employed by the company under the Foreign Workers Compensation Scheme (FWCS).

ACPG Principal Insurer  is one of the panel insurance companies appointed and approved by the Ministry of Human Resources to underwrite FWCS. The scheme provides foreign workers with personal accident and repatriation benefits during and outside of working hours.

COVERAGE

Foreign workers who are under the employment of the insured company will enjoy coverage that include

  • Death and disability due to an accident
  • Disease arising out of and in the course of employment
  • Medical expenses
  • Repatriation expenses

Foreign Workers Hospitalization & Surgical Scheme (FWHS)

Effective 1 January 2011, all foreign workers in Malaysia are required to purchase a RM120 premium per year Foreign Workers Hospitalization & Surgical Scheme (FWCS) that provides RM20,000 annual coverage.

ACPG Principal Insurer is one of the panel insurance companies appointed and approved by the Ministry of Health (MOH) to underwrite the FWHS.

BENEFITS

Under the insurance policy, foreign workers will enjoy benefits that include

  • Daily hospital and room board of up to a maximum of 30 days
  • Intensive care unit (ICU) of up to a maximum of 15 days
  • Operating theatre fees
  • Surgical fees
  • Anaesthetist fees
  • In-hospital physician visits of up to a maximum of 30 days
  • In-hospital specialist consultation visits of up to a maximum of 30 days
  • Ambulance fees
  • Medical report fees

Foreign Workers Insurance Guarantee (FWIG)

Foreign Workers Insurance Guarantee (FWIG) is a guarantee required by the Immigration Department from the employer as a security deposit for the employment of foreign workers (excluding Domestic Maid) under Regulation 21 of the Immigration Regulations.

This insurance serves as a guarantee to the Immigration Department to cover the repatriation expenses in the event the foreign worker is required by the authorities to be sent back to his/her country of origin during his/her course of stay in Malaysia. The circumstances could arise from:-

  • Breach of Immigration Act
  • Foreign worker is caught involving in illegal and illicit activities such as drug, immoral work, etc.
  • Employer goes into liquidation and is unable to provide the return passage for the foreign worker

Please refer to the policy contract for the full details of benefits, terms and exclusions that are applicable.

The information provided here is a brief summary for quick and easy reference.

The exact terms and conditions that apply are stated in the policy contract.

Your Trusted Construction Insurance Risk Management Advisory Company since Year 1989.

ACPG Management Sdn Bhd

Head Office

158-3-7, Blok 158, Kompleks Maluri,

Jalan Jejaka, Taman Maluri, Cheras,

55100 Kuala Lumpur, Malaysia.

http://www.acpgconsultant.com

+603-92863323

Shopping Mall Public Liability Insurance Kuala Lumpur Malaysia Directory

acpg100Fb_m-public-liability.jpg

Shopping Mall Public Liability Insurance Kuala Lumpur Malaysia

Public Liability Insurance

Arranged By

ACPG Management Sdn Bhd

Head Office

158-3-7, Blok 158, Kompleks Maluri,

Jalan Jejaka, Taman Maluri, Cheras,

55100 Kuala Lumpur, Malaysia.

http://www.acpgconsultant.com

+603-92863323

 

Shopping Mall installation liability insurance FB Wall Post

Public Liability insurance is considered essential in businesses which involve regular interactions between the members of the public and the company such as retail businesses, restaurants, clinics, contractors, renovators, installers  and many more.

The Public Liability insurance covers your legal liability to a third (3rd) party as a result of an accident happening in connection with your business operations.

 

The insurance indemnifies you against all sums which you become legally liable for damages and claimant’s costs and expenses in respect of:

Bodily injuries including illnesses to any person.

Losses or damages to property.

Legal expenses incurred in your legal proceeding defence.

 

Public Liability insurance protects our policyholders against legal liabilities arising in connection with their business operations.

 

Coverage may include products, completed operations, premises and operations, personal injury and contractual liability.

These are some of the types of coverage requested:

Premises and operations coverage for bodily injury or property damage incurred on their premises and/or as a result of their business operations

 

Product liability coverage for bodily injury or property damage incurred through the use of the product manufactured, distributed or sold

 

Completed operations coverage for bodily injury or property damage incurred because of a defect in a completed project.

 

Public Liability Insurance for

Construction Contractors and Sub Contractors.

Renovation Contractors and Sub Contractors.

Installation Contractors and Sub Contractors.

Signboard Owner, Contractors and Sub Contractors.

Manufacturing and Factory Owners

Office Owners and Tenants

Shop, Retail Outlets Owners and Tenants.

Shopping Mall Owners, Tenants and JMB, MC, PMC, property management company and management office.

 

acpg100Fb_installation

Shopping Mall Public Liability Insurance Listing

AEON Mahkota Cheras Shopping Mall Public Liability Insurance

AEON Alpha Angle Shopping Mall Public Liability Insurance

AEON Maluri Shopping Mall Public Liability Insurance

Alamanda Putrajaya Shopping Mall Public Liability Insurance

Amcorp Mall Shopping Mall Public Liability Insurance

Ampang Park Shopping Mall Public Liability Insurance

Ampang Plaza Shopping Mall Public Liability Insurance

Ampang Point Shopping Mall Public Liability Insurance

Atria Shopping Mall Public Liability Insurance

Avenue-K Shopping Mall Public Liability Insurance

Bangsar Village Shopping Mall Public Liability Insurance

Bangsar Shopping Mall Public Liability Insurance

Bangsar South Shopping Mall Public Liability Insurance

Bangsar Trade Centre Shopping Mall Public Liability Insurance

Berjaya Times Square Shopping Mall Public Liability Insurance

Bukit Raja Shopping Mall Public Liability Insurance

Brem Mall Shopping Mall Public Liability Insurance

Campbell Complex Shopping Mall Public Liability Insurance

Capsquare Shopping Mall Public Liability Insurance

Carrefour Kepong Shopping Mall Public Liability Insurance

Carrefour Jalan Peel Shopping Mall Public Liability Insurance

Carrefour Wangsa Maju Shopping Mall Public Liability Insurance

Cheras Leisure Mall Shopping Mall Public Liability Insurance

Da Men USJ Shopping Mall Public Liability Insurance

Digital Mall Shopping Mall Public Liability Insurance

Empire City Shopping Mall Public Liability Insurance

Endah Parade Shopping Mall Public Liability Insurance

Equine park Shopping Mall Public Liability Insurance

EVOLVE Concept Mall Shopping Mall Public Liability Insurance

Fahrenheitt 88 Shopping Mall Public Liability Insurance

Four Seasons Place Kuala Lumpur Shopping Mall Public Liability Insurance

Goldcourse Shopping Mall Public Liability Insurance

Great Eastern Mall Shopping Mall Public Liability Insurance

Hartamas Shopping Mall Public Liability Insurance

Idaman Plaza Shopping Mall Public Liability Insurance

Ikano Power Centre (IPC) Shopping Mall Public Liability Insurance

IKEA Shopping Mall Public Liability Insurance

INTERMARK Retail Podium Shopping Mall Public Liability Insurance

IOI City Mall Putrajaya Shopping Mall Public Liability Insurance

IOI Mall Shopping Mall Public Liability Insurance

Jaya One Shopping Mall Public Liability Insurance

Jaya 33 Shopping Mall Public Liability Insurance

Klang City Square Shopping Mall Public Liability Insurance

Klang Parade Shopping Mall Public Liability Insurance

Klang Utama Shopping Mall Public Liability Insurance

Komplek Muhibah Seksyen 24 Shopping Mall Public Liability Insurance

Kompleks Elektronik ACE Shopping Mall Public Liability Insurance

Kompleks Galaxy Ampang Shopping Mall Public Liability Insurance

Kompleks Kota Kajang Shopping Mall Public Liability Insurance

Kompleks Mutiara Shopping Mall Public Liability Insurance

Kompleks Centre Point Shopping Mall Public Liability Insurance

Kompleks Showplex Mont Kiara Shopping Mall Public Liability Insurance

Kompleks Sungai Buloh Shopping Mall Public Liability Insurance

Kota Raya Shopping Mall Public Liability Insurance

Low Yat Plaza Shopping Mall Public Liability Insurance

Lot 10 Shopping Mall Public Liability Insurance

Maju Junction Shopping Mall Public Liability Insurance

Metro Prima Shopping Mall Public Liability Insurance

Metro Point Kajang Shopping Mall Public Liability Insurance

Midvalley Mega Mall Shopping Mall Public Liability Insurance

One Utama Shopping Mall Public Liability Insurance

Pavillion Kuala Lumpur Shopping Mall Public Liability Insurance

Pear Point Shopping Mall Public Liability Insurance

Pertama Complex Shopping Mall Public Liability Insurance

Pingat Bazaar Shopping Mall Public Liability Insurance

Plaza City One Shopping Mall Public Liability Insurance

Plaza Metro Kajang Shopping Mall Public Liability Insurance

Plaza Shah Alam Shopping Mall Public Liability Insurance

Publika Shopping Mall Public Liability Insurance

Puchong Tesco Shopping Mall Public Liability Insurance

Pudu Plaza Shopping Mall Public Liability Insurance

Roppongi Cyberjaya Shopping Mall Public Liability Insurance

SACC Mall Shopping Mall Public Liability Insurance

Selayang Star City Shopping Mall Public Liability Insurance

Setia City Mall Shopping Mall Public Liability Insurance

Shaw Parade Shopping Mall Public Liability Insurance

SOGO Shopping Mall Public Liability Insurance

South City Plaza Shopping Mall Public Liability Insurance

Star Avenue Lifestyle Mall Shopping Mall Public Liability Insurance

Star Hill Gallery Shopping Mall Public Liability Insurance

Subang Parade Shopping Mall Public Liability Insurance

Summit USJ Shopping Mall Public Liability Insurance

Sungei Wang Plaza Shopping Mall Public Liability Insurance

Sunway Giza Shopping Mall Public Liability Insurance

Sunway Nexis Shopping Mall Public Liability Insurance

Sunway Putra Mall Shopping Mall Public Liability Insurance

Sunway Pyramid Shopping Mall Public Liability Insurance

Sunway Velocity Shopping Mall Public Liability Insurance

Suria KLCC Shopping Mall Public Liability Insurance

Tropicana City Mall Shopping Mall Public Liability Insurance

The Curve Shopping Mall Public Liability Insurance

The Gardens Mall Shopping Mall Public Liability Insurance

The Mall Shopping Mall Public Liability Insurance

The Mines Shopping Mall Public Liability Insurance

The Weld Shopping Mall Public Liability Insurance

THE 19 USJ City Mall Shopping Mall Public Liability Insurance

Vivahome Shopping Mall Public Liability Insurance

Wangsa Walk Mall Shopping Mall Public Liability Insurance

Contractor Liability Insurance FB A4

Construction Insurance Kuala Lumpur Malaysia

acpg100Fb_contrac

Construction Insurances Explained

– Contractors’ All Risks Insurance

Contractors’ All Risks Insurance

There are several terms used in the insurance world that mean different things to different people and one of these is Contractors’ all risks (CAR) insurance. The term is sometimes used to refer to both the material damage and liability covers required by a Contractor. Most insurance practitioners would regard CAR as referring only to the material damage cover on the contract works unless the real intention was obvious from the rest of the text. Anyone using the term, whether verbally or in writing, should make their intention clear, so as to avoid any ambiguity in interpretation.

CAR covers what is stated within the actual insurance policy for which the premium is paid. The Employer has the opportunity to specify his requirements as to what is to be included within the CAR within the contract if the Contractor is responsible for the provision of such insurance alternatively the Employer specifies the cover within the policy he takes out where the Contractor is not obligated to provide insurance under the Contract.

A CAR policy provides insurance coverage when the Works being constructed, as defined in the Contract, are damaged by an insured peril and require replacing and/or repairing. It is normal for the Contract to stipulate who will provide this cover. If it were the Contractor then it would be normal for them to take out a specific policy to cover the project or alternatively if available to them add it to a policy covering all their contracts up to a specific limit. In the event the responsibility should fall upon the Employer then cover would normally be under a policy arranged specifically for that project.

When arranging the CAR coverage for a project it is essential that care be taken in identifying the correct Contract Value, Construction Period, Defects Liability Period and Description of the Works. The policy will normally cover any physical loss or damage unless the cause is specifically excluded, thus the term ‘All-Risks’ whilst commonly used, is to some extent, misleading. Nevertheless the cover is very wide and embraces protection against fire, aircraft, explosion, earthquake, riot, malicious damage, storm, flood, burst pipes, impact and other accidental damage. However, CAR policies can be issued covering loss or damage by particular and specified perils, e.g. fire, flood, storm. In both cases the policy should generally be extended to provide protection in respect of damage by terrorists where such is commercially available.

In addition material damage to the Works or the machinery being erected CAR generally includes coverage for third-party liability for bodily injury and property damage to the surrounding properties. The policy can in some circumstances be extended to include consequential losses or losses due to delay in start-up following loss or damage under material damage section. This cover is also called advanced loss of profit.

Either way it is imperative that the parties fully understand what exclusions apply or which perils are listed to ensure that the cover gives sufficient protection to the Employer and the Contractor. The Sum to be insured under CAR should be adequately calculated and must include at least the Contract Value, value of Contractors’ plant and machinery, value of Employers existing property, estimated cost of debris removal, value of all temporary facilities, tax and an allowance for inflation. In addition it is wise to make sure that on site as well as offsite storage facilities are included under the policy together with the value of any free issue materials where the Employer transfers the risk to the Contractor under the Contract.

The policy should always be in the joint names of the Employer and Contractor although the Contract may stipulate that the Bank or Financing institutions are also named in the policy, depending upon their specific requirements for providing project financing.

Joint names insurance is where two or more parties (for example the Employer and the Contractor) are jointly insured under a single policy. Each party has legal rights under the policy and can claim against the insurer, but the insurer has no right of subrogation against the other insured party.

It is important to remember that each party is bound by the normal rules, and to avoid any difficulties each should individually comply with the duties of disclosure and notification.

Having an interest noted on a policy is very different and is rarely an acceptable substitute for a joint names policy.

A third-party is not a party to the contract of insurance, and thus cannot claim against the insurer. Similarly, it does not prevent the insurer from exercising rights of subrogation against the third-party.

PAM, IEM, FIDIC and generally most standard forms of contract contain fairly detailed provisions for property and liability insurance. Generic amendments to these insurance provisions are not normally essential, however, discreet changes may be required depending on the nature of a specific project (for example, amending the definition of joint names insurance policy to include the project funders, or to reconcile the standard provisions with a project insurance policy taken out by the Employer).

All CAR policies will have an excess that will be deducted from any claim settlement. On occasions insurers will apply more than one excess under a policy for specific losses where a certain risk warrants such and additional excess being imposed.

In addition generally most policies include exclusions for which extensions of CAR coverage maybe granted or included within the CAR coverage of the CAR policy may be extended to cover such as:

(A)        professional fees;

(B)        automatic reinstatement of the policy limit following a loss;

(C)        debris removal;

(D)        free issue materials;

(E)        discovery of munitions of war;

(F)         inflation clause;

(G)        plans and documents;

(H)        others.

Individual insurance providers specialising in this class of insurance will also have their own list of extensions that they will negotiate with insurers. As an example you may refer to the example provided which is so provided as an example and these will vary depending upon the general insurance market at the time the CAR insurance is taken out by the insuring party.

In addition the parties need to consider if the CAR policy is to cover the respective party’s to the Contract for:

Additional cost of construction of un-built works in the event of

(A) Inflationary Costs

(B) Out of sequence working

(C) Defective design, materials and workmanship

(D) Extended defective condition exclusion

(E) Limited defective condition exclusion

(F) Design improvement exclusion

It is understood that various legal challenges are currently on-going as to the validity of these clauses and therefore whilst the description of coverage above may not reflect the current or future legal interpretation. As with all contractual documentation it is recommended that all parties seek professional advice in respect of these risks.

It should be noted here that if the Contractor arranges CAR cover it may restrict or even remove the ability of the Employer to purchase any consequential loss coverage.

acpg100Fb_bond-insurance.jpg

Construction Insurances Explained

– Public Liability Insurance

Public Liability Insurance

Typical public liability insurance will provide indemnity in respect of liability at law for damages arising from accidental injury to third parties (not employees) or accidental damage to third-party property arising in connection with the project. It may also cover liability for damages arising out of any nuisance or trespass committed by the insured and any rights (such as a right of way) with which the insured may accidentally interfere in the course of the development. Other elements of cover normally provided include defence of claims costs, the use of plant on the site and legal defence costs in respect of prosecutions brought under the Health and Safety legislation.

Many insurance providers now exclude claims arising from sources they regard as particularly hazardous, such as terrorism, asbestos, gradual pollution, mould, e-commerce transactions and, potentially, financial loss where there has been no ‘injury or damage’ as defined in the policy. Insurers may restrict their liability for particular risks by imposing inner limits much smaller than the overall policy limit.

Public liability insurance coverage may be arranged on an annual basis with a specific limit being the maximum amount payable in the event of any one claim or series of claims arising from one occurrence. It is normal for this limit to apply in respect of any one claim but some limits do apply to all claims in the period of insurance. There may be a limit on any one claim and then a separate aggregate limit. Sometimes there are elements of cover that insurers may be particularly concerned about, e.g. sudden and accidental pollution may be subject to lower limits of liability and/or separate aggregates.

Whatever type is issued, it is the insured party or parties that decide on the level of cover to be purchased dependent upon the risk exposure arising from the work being undertaken. When deciding upon the limits to be purchased it is best not to rely on any figure requested within a contract document, as this is normally the minimum amount required. The policy will normally be subject to an excess that will be deducted from the total amount claimed and may apply only in respect of claims for property damage or in respect of all claims.

Every party on site with a potential liability to the public will require an insurance policy. Additional responsibilities for each party will also be set out in the contract. It is traditional and still common for the Contractor to arrange a cover on behalf of the Employer. However, it has to be asked if this is in the best interests of everyone, whether the Employer who may find he has only nominal cover or a claimant who may find they are passed from one insurer to another if there are different policies in different names. One option is to effect a project policy arranged by the Employer.

The parties protected by the policy will vary according to the Employer’s requirements and the nature of the contract forms being adopted. The indemnity can apply to the Employer only or together with the Contractor, his subcontractors and tradesmen. In addition there may be freeholders, superior landlords, financiers plus professional consultants and suppliers (on site exposures only) to be added to the list of insured. The policy should set out the names of all insured and specify in which policy covers they have an insurable interest.

Public liability insurance is not a cheap insurance and if one party does arrange cover in two or more names the cost of this and the potential savings to the other names should to be reflected in tender prices.

It is important for the Employer to decide responsibilities for placing public liability insurance before contracts are signed, rather than just follow the provisions of the basic contract conditions. Whoever is making the decision as to who must arrange the cover must consider all those who may need to be protected.

acpg100Fb_installation

Construction Insurances Explained

– Existing Building Insurance

Existing Building Insurance

Where an existing building is to be the subject of Contract Works care is needed by those responsible for drawing up the contract conditions and those responsible for insuring the building. The insurance of new build contract is relatively straightforward compared to the difficulties that can arise when an existing building is being worked upon. Such a building will in most circumstances be insured under a commercial all risks property owners’ policy whilst occupied or temporarily unoccupied pending the works. There will be a number of conditions in that policy that will apply when works are being carried out and these should be examined. If the contract does not involve much of an increase in risk the current insurers may be happy to continue the cover without additional charge but it will require reasonable precautions to be taken. On the other hand if there is hot work involving welding equipment or blowtorches, they may require an additional premium and/or risk improvements. If there are to be structural alterations, particularly if they involve foundations, insurers may wish to reconsider the cover and, say, exclude subsidence occurring as a result of the works. The remaining subsidence risk may then be insured under a non-negligence policy at terms reflecting the insurance providers’ assessment of the revised risk. The specific action will depend on the particular circumstances and the attitude of the insurance provider. However, it is also possible that the current insurer will wish to exclude the cover altogether on the grounds that the building is now a construction risk and best insured under a construction policy. The problem with this is that the construction insurance market does not always have the capacity to insure a substantial building.

Contractors often seek to take out joint names insurance with the Employer in respect of the existing building as they wish to avoid taking out public liability insurance due to the high premiums for a large building. This is all very well if the Employer is also the insured under the policy and is prepared to pay any additional premium and/or to accept restrictions in cover and/or to pay for additional risk precautions during the contract period. Either way it should be made clear that this is at the Employer’s risk.

Problems start if the insurers of the building do not want to carry the additional risk. Alternatively the Employer may not control the buildings insurance and the landlord or freeholder that does may refuse to agree to joint names status for the Contractor. If either of these eventualities arises, a solution has to be found. There are solutions or partial solutions but they may be very expensive and still leave the Employer carrying some risk.

Where the Contract Works will include very little of the original building, perhaps just the exterior walls or the facade, it may be better to cover both the existing building and the contract works under the CAR policy with one sum insured. It should be cheaper and make settlement of any claims easier. A CAR policy is designed for construction works and the cover is drawn up to reflect the risks inherent in construction. There are elements of the cover that may make it beneficial to insure the existing building under such a policy,

The insurance providers for the existing building must be advised of the nature and extent of the Contract Works or the policy could be invalidated. However, it may be better to cover the existing building under an all-encompassing CAR policy, as mentioned above.

Where the Employer is undertaking to arrange a joint names cover on the existing building to protect the Contractor, he should make sure this is possible. If the Employer is a lessee or has not arranged the policy there could be problems that are both time-consuming and expensive for the Employer to resolve.

acpg100Fb_firecon

Construction Insurances Explained

– Consequential Loss Insurance

Consequential Losses Insurance

Property Developers have to carry risks it is part and parcel of their business. The risk due to consequential losses on a construction site is a high one as there are so many factors that could delay completion and then so many headings under which additional expense or actual loss of anticipated income could arise. The measurement of each potential loss can be a problem and if not correctly assessed there may be underinsurance or an unnecessarily high premium being paid.

If any party involved with the construction will require consequential loss cover of any kind it is very unlikely that any insurer will be willing to assist unless it also provides the CAR insurances on the Contract Works. The reason for this lies with the fact that only by the insurer controlling the settlement of the material damage claim can the size of the consequential loss be minimised. Therefore, if the Contract Conditions call for the Contractor to arrange insurance on the works, it may be impossible for the Employer to arrange any consequential loss cover. The Employer will then have to arrange its own cover on the Contract Works in order to secure that consequential loss protection.

To avoid the possibility of the Employer effectively paying enhanced premiums for such Contract Works cover it is worthwhile making clear to the Contractor from the outset that the Employer is paying for its own cover, if this is the intention. The contract price quoted by the Contractor should then reflect this.

It is usually very difficult, if not impossible, to persuade the Contractor to reduce its price at a later date. In any case the Contractor may prefer to arrange its own cover on the Works so that he has control over any claims that may arise. This is understandable and the Contractor may also argue, possibly with some justification, that it can buy the CAR insurance more cheaply than the Employer. Faced with the problems of changing contract conditions, arranging cover on the works and, possibly, paying a higher premium for the privilege, any Employer could be forgiven for giving up the idea of arranging consequential loss cover.

It is not good practice to rely solely on liquidated damages instead. Apart from the fact that the Contractor may find it impossible to purchase insurance against liquidated damages, making recovery of a genuine loss uncertain, there is the possibility that the Contractor will be entitled to an extension of time under the Contract and will not be liable to pay any damages anyway. Properly arranged insurance for consequential losses will more accurately reflect the Employer’s loss than liquidated damages can and by arranging both CAR and consequential loss insurance with the same insurers there is the added advantage that the insurers will be looking for a quick resolution to any CAR claim in order to reduce the size of the consequential loss.

Under all the Standard Forms of Contract commonly used in Malaysia for construction works there exists clauses which make the Contractor obliged to compensate the Employer to the extent of liquidated and ascertained damages at the rate specified in the Contract. However, if the delay is due to certain relevant events an Extension of Time for completion of the Works will be given which will result in the Contractor not being obliged to pay any such damages.

Typically these relevant events would include:

A)  force majeure;

B)  exceptionally adverse weather conditions;

C)  loss or damage occasioned by any one or more of the specified perils (see below);

D)  civil commotion, local combination of workmen, strike or lock-out affecting any of the trades employed upon the works or any of the trades engaged in the preparation, manufacture or transportation of any of the goods or materials required for the works;

E)   terrorism.

Contract Conditions do vary and therefore the proposal that an extension of time may be available is not necessarily correct in every instance.

The specified perils are normally defined as: fire, lightning, explosion, storm, tempest, flood, bursting or overflowing of water tanks, apparatus or pipes, earthquake, aircraft and other aerial devices or articles dropped therefrom, riot and civil commotion, but excluding excepted risks. The excepted risks include, amongst other things, radioactivity and pressure waves.

Force majeure may be defined in the Contract however as all contract are normally executed and subject to the laws of Malaysia consideration should also be taken of the definition of force majeure contained within the Contracts Act and adopted by the Courts. For insurance purposes the principal force majeure perils include: fire and allied perils, strikes, lockouts, labour disputes, change of law, order of any court enforcing a change of law and any other cause beyond the control of the Contractor.

It was possible to buy commercially viable cover for the consequential losses flowing from late completion or permanent abandonment of a project following the occurrence of force majeure perils or restricted to limited specified peril but following some extremely large claims it is now very difficult to obtain such coverage at commercially viable rates.

Where an insurance policy makes reference to All-Risks of Specified Perils the coverage will almost certainly include not just those mentioned above but, in addition, malicious damage, impact, subsidence, landslip, heave and, possibly, other accidental damage. Again such insurance is getting harder and harder to obtain and even flood coverage is being limited after the events of 2011 in Thailand.

Where liquidated and ascertained damages can be applied due to any delay scenario, the reality of the impact upon the Employer’s financial position can often be beyond the level of liquidated and ascertained damages set during tender negotiations. Whilst every effort is made to set the level of damages at an appropriate level, the full consequences are not often appreciated until a loss is sustained. Equally, it can be the case that on smaller projects it is difficult to reach agreement with the Contractor involved for an appropriate level of damages. This is because, if set accurately, they may preclude the Contractor from undertaking the development or, alternatively, the imposition of such damages would adversely affect any tender amount submitted.

Consider the scenario where an Employer is constructing a commercial development and has entered into lease or purchase agreements with a tenant. It may not simply be the Employers loss in rental which needs to be considered but also the tenant’s losses which result from delays. The amount of such damages will depend greatly on the activities and circumstances of the tenant and the content of the Employers lease or purchase agreement with that tenant.

Unfortunately, Employer’s acting as developers often carry more risk than is necessary by failing to insure or insure adequately, even though insurance cover can be purchased. Employers should at least consider taking insurance coverage for the following potential risks:

1)   Loss of Rent/Revenue and Loss of Use of Sale Proceeds, including Assessment of Indemnity Period.

The loss of rental income/revenue income from use or the Employer being prevented from investing or using the proceeds of a sale are straight forward concepts even if their estimation may not be so. The indemnity period refers to the time limit imposed in a policy for which the Employer may claim losses as a result of event which allows the Employer to claim consequential losses. Thus Employers need to consider the period required to rebuild the project or how long it may take for the resale or re-letting following such rebuilding.

2)   Expediting Costs (Additional Cost of Working)

Cover for expediting costs relates to the additional costs in executing and repair or rebuilding works over and above any amount recoverable under the CAR insurance covering the Contract Works. The amount recoverable is generally limited to what is reasonable compared to the saving produced on the claim for losses due to delays in completion. In practice this means that insurers will be reluctant to pay for expenditure that did not produce at least a corresponding saving on another part of the claim.

3)   Costs Incurred in Raising or Extending Loans

The legal and other costs incurred in continuing existing loans or raising new ones as a result of delay by insured damage should also be covered. These may be included within the cover for lost rental income/revenue income or delays in repatriation of proceeds cover referred to above without the need for a separate sum insured.

4)   Additional Overhead Costs

A delay in completion of the Works may incur the Employer in additional costs involving marketing, leasing, selling and legal costs in the case of a developer or where the facility will be used to manufacture or operate a business there could be additional rental costs, redundant employee costs, no productive machinery costs and many other increased overheads.

5)   Higher cost of development finance

Many covers that are arranged which ignore the fact that development finance can cost more than finance secured against a completed project and that the level of borrowing which can be secured against a completed project is normally greater. The consequences of this are twofold. One being the increased cost of borrowing and secondly that more capital is tied up in the project for a longer period as a result of not being able to re-finance the loan against the completed project.

6)   Additional Increase in Cost of Working Cover

It had been addressed that generally the Employer will be limited to reasonable cost of expediting completion of the Works. It may be possible to obtain cover over and above this to further expedite the works by means of an additional item although sometimes the matter is dealt with by means of an extension to the cover with an inner limit. The ability to make a claim under expediting costs might give the Employer useful options in the event of a loss. For example, the ability to make extra payments to speed up completion may enable them to avoid losses in the future that would fall outside the indemnity period.

7)   Damage Away from the Site including Prevention of Access

Where CAR policies exclude coverage for losses that result from damage off site be it to the Contractors’ offices, materials or equipment stored off site, vehicles or plant in transit or whilst stored and damage to other phases of development It is prudent for the Employer to consider extending coverage and also insuring for such events as denial of access and/or failure of utilities.

8)   Damage at suppliers’ premises

Some CAR policies offer limited cover in respect of delays incurred following damage at the premises of suppliers of materials to be used in the Contract Works. The most serious losses are likely to occur if there is a delay in the arrival of crucial or bespoke supplies such as lifts, special equipment and the like. And the limits of cover normally fail to adequately protect the Employer. Accordingly it is prudent for the Employer to consider the purchased sufficient levels of cover for delays as a result of damage to all suppliers to the development not named on other policies although such insurance can be very expensive, especially where suppliers are importing goods from outside of Malaysia.

To summarise an Employer who is seeking Consequential Loss Insurance will be better off arranging the CAR Insurance for the Contract Works or alternatively an all-encompassing Project Insurance. Consequential Loss Insurance is a generally considered a more certain route to recovery of Employer costs than reliance solely on liquidated damages. Consequential Loss Insurance will be a more accurate reflection of the Employer’s loss risks than liquidated damages and finally in Malaysia the recovery of Liquidated damages from a Contractor still requires the Employer to prove his losses if challenged in the courts, thus regardless of the sum stated in the Contract this does not guarantee the amount will be recovered, which will be dependent upon the extent to which the Contractors is liable under the contract for the Employers costs.

In order for the Employer to secure adequate Consequential Loss Insurance at a competitive rate he should ensure that those responsible for arranging the policy have a full understanding of how the project is to be financed, the programming of the Works and the financial implications of any delay.

Foreign Worker Insurance FB Wall Post 2

Construction Insurances Explained

– Workmen Compensation Insurance

for Contractors, Builders & Other Construction Professionals

Construction and contracting professionals know all too well the risks of their industry. From on-the-job accidents to illnesses from handling hazardous materials, even the best-prepared carpenter can be the victim of unforeseen events.

If one of your subcontractors is hurt due to malfunctioning equipment or falls ill due to exposure to asbestos-containing materials (ACM), your construction and contracting business could be held responsible. Workers’ Compensation Insurance is the protection construction and contracting business owners rely on to cover the medical expenses related to an employee’s injury or illness or for the earnings the employee missed while recovering.

Read on to learn how you can protect your construction and contracting business and your employees from uncertainty with Workers’ Compensation Insurance.

Workers’ Compensation Insurance: Protecting Contractors

The dangers of operating industrial machinery, the exposure to potentially hazardous materials, and the toll of repetitive motion injuries are all risks contractors face daily. And while safety training and personal protective equipment are a necessary risk management tools, construction and contracting businesses know accidents happen all the time.

Workers’ Compensation Insurance helps offset some of the risks you can’t avoid by providing coverage that protects your construction and contracting business assets in the event of a costly lawsuit brought by an injured or ill employee. With an adequate policy, you know your construction and contracting business will have the necessary funds to cover court costs and settlements should unexpected accidents and lawsuits occur.

As a rule, Workers’ Compensation is currently necessary for all businesses with employees, though the laws vary from state to state. For example, North Dakota, Ohio, Washington, and Wyoming have monopolistic markets, which means the state sets rates and operates a state-administered fund of Workers’ Compensation Insurance. private employers can choose whether or not to carry Workers’ Compensation Insurance coverage.

How Construction & Contracting Professionals Benefit from Workers’ Compensation Insurance

While some contractors know this coverage as “workman’s comp” or “workers’ liability insurance,” Workers’ Compensation Insurance acts as a safety net for your construction and contracting business by covering the costs of…

Medical expenses relating to the employees’ on-the-job injuries and work-related illnesses. 

Wages your employee would have earned if they were able to perform their work. 

Legal fees should your employee file a lawsuit against your construction and contracting business for their work-related injury or illness.

Because on-the-job accidents can quickly lead to lawsuits, most Workers’ Compensation policies also include Employers’ Liability Insurance. If your injured or ill employee sues your company, this policy will help pay for the legal costs of defending against the claim.

And legal fees add up quickly. Between attorney’s fees and the time lost from work to attend court, your construction and contracting business could suffer a deep financial burden even if the court finds that your business is not responsible for the illness or injury.

Construction Insurance FB A4

What is Contractors’ All Risks & Erection All Risks insurance?

These 2 policies are designed to meet the insurance obligation placed upon Contractors under the contract conditions.

  • Contractors’ All Risks
    Covers buildings and civil engineering works under construction
  • Erection All Risks
    Covers plants, machinery, equipment and steel structures like bridges in the course of erection

Key coverage

Here is an overview of your coverage

Contractors’ All Risks / Erection All Risks

  • Material Damage
    Covers against sudden and unforeseen physical loss or damage to contract or erection works/property/items  
  • Third Party Liability
    Covers third party liability for which we shall become legally liable to pay as damages consequent upon
  • Accidental bodily injury or illness of third party
  • Accidental loss or damage to property belonging to third party
    Occurring in direct connection with the works and happening at or in the immediate vicinity of the site.
    The indemnity is also provided for legal costs and expenses provided the liability is within the limit of liability insured.

Previous Older Entries